Terms and Condition

Nutric Enterprises Terms and Conditions

Last Updated: June 2025

Welcome to [Nutric Enterprises /Digital Standee Manufacturers]. By using our website, sending an enquiry, requesting a quotation, or purchasing our products or services, you agree to these Terms & Conditions. If you do not agree, please do not use our website or services.

1. About Nutric Enterprises

Nutric Enterprises is a trusted manufacturer, supplier, installer, and service provider of:

2. Website Usage

You agree to use our website only for legal purposes.Please do not:
  1. Try to access our website or servers without permission.
  2. Upload viruses or harmful software.
  3. Copy or use our content, images, or designs without our written permission.
  4. Use our website for any illegal or fraudulent activity.

3. Intellectual Property

All content on this website, including our logo, images, product designs, videos, graphics, and text, belongs to Nutric Enterprises.You cannot copy, modify, or use any content without our written permission.

4. Product Information

We are trying our best to keep all product information updated.However:
  • Product specifications may change without notice.
  • Product images are for reference only.
  • Actual colours, sizes, and appearance may vary slightly.
  • Custom-made products may look different based on customer requirements.

5. Quotations & Orders

Quotations are valid only for the period mentioned in the quotation.Orders are confirmed only after written approval and advance payment (if applicable).Manufacturing of customized products starts after final approval.We reserve the right to accept or cancel any order.

6. Pricing & Payment

Prices may change without prior notice.GST and other applicable taxes will be charged as per government rules.Transportation, installation, and service charges may be extra unless mentioned.Delay in payment may delay production or delivery.

7. Manufacturing, Delivery & Installation

We always try to deliver products on time.However, delivery may be delayed due to:
  • Production requirements
  • Transport delays
  • Raw material availability
  • Natural disasters
  • Government restrictions
  • Other unexpected situations
Customers should ensure that the installation site is ready before installation.

8. Warranty

Warranty details are provided with the quotation or invoice.The warranty does not cover:
  • Physical damage
  • Water or liquid damage
  • Electrical voltage issues
  • Improper installation by others
  • Misuse or negligence
  • Unauthorized repairs or modifications

9. Returns & Replacement

Customized or made-to-order products cannot be returned or refunded. Any transport damage should be reported within 48 hours of delivery.Replacement requests will be checked and approved after inspection.

10. Limitation of Liability

Nutric Enterprises is not responsible for losses caused by:
  • Product malfunction
  • Business interruption
  • Loss of profit
  • Data loss
  • Delivery delays
  • Website usage issues
Our maximum responsibility is limited to the amount paid for the product or service.

11. Third-Party Websites

Our website may contain links to other websites. We are not responsible for their content, services, or privacy policies.

12. Privacy

By using our website, you also agree to our Privacy Policy, which explains how we collect and use your information.

13. Changes to Terms

We may update these Terms & Conditions at any time without prior notice. The updated version will be available on this website.

14. Governing Law

These Terms & Conditions are governed by the laws of India. Any legal dispute will be handled by the courts in Noida, Uttar Pradesh.

15. Customer Responsibilities

Customers are requested to provide accurate information while placing enquiries or orders. Before installation, customers should ensure that the installation location has proper power supply, internet connectivity (if required), and sufficient space for installation. Any delay caused due to site readiness may affect the delivery or installation schedule.

Digital Standee Manufacturers : Contact Details

For any questions regarding these Terms & Conditions, please contact us using the details above.